The subject matter of the Public Contract is supply of instrument shutter as a part of the “Beamline for European Engineering Research” (BEER) instrument, including manufacture, documentation and other performance in accordance with the Contract including its Annexes and delivery of the System to the Buyer at the ESS address in Lund, Kingdom of Sweden, including a free licence to use the System for the needs of the Project and its follow-up phases and installation and alignment of the System.
Termín
Lhůta pro podání nabídek byla 2022-03-04.
Veřejná zakázka byla zveřejněna na 2022-01-27.
Oznámení zadávacího řízení (2022-01-27) Zadavatel Jméno a adresy
Název: Ústav jaderné fyziky AV ČR, v. v. i.
Národní registrační číslo: 61389005
Poštovní adresa: Husinec - Řež, čp. 130
Poštovní město: Husinec, Řež
Poštovní směrovací číslo: 25068
Země: Česko 🇨🇿
Kontaktní osoba: HOLEC, ZUSKA & PARTNEŘI advokátní s.r.o.
Telefon: +420 296325235📞
E-mail: zakazky@holec-advokati.cz📧
Region: Střední Čechy🏙️
ADRESA URL: https://www.ujf.cas.cz🌏
Adresa profilu kupujícího: https://ezak.ujf.cas.cz🌏 Komunikace
Adresa URL dokumentů: https://ezak.ujf.cas.cz/?lang=en🌏 Další informace lze získat od
Název: HOLEC, ZUSKA & PARTNEŘI advokátní s.r.o.
Národní registrační číslo: 07759711
Poštovní adresa: Radlická 3185/1c
Poštovní město: Praha
Poštovní směrovací číslo: 150 00
Země: Česko 🇨🇿
Kontaktní osoba: Mgr. Jan Dudák, advokát
Telefon: +420 296325235📞
E-mail: zakazky@holec-advokati.cz📧
Region: Praha🏙️
ADRESA URL: http://www.holec-advokati.cz/🌏
Adresa URL kupujícího: https://ezak.ujf.cas.cz🌏 Komunikace
Adresa URL účasti: https://ezak.ujf.cas.cz/vz00000515🌏
Objekt Rozsah veřejné zakázky
Název: Instrument Shutter for the diffractometer BEER at ESS
Produkty/služby: Laboratorní, optické a přesné přístroje a zařízení (mimo skel)📦
Krátký popis:
“The subject matter of the Public Contract is supply of instrument shutter as a part of the “Beamline for European Engineering Research” (BEER) instrument,...”
Krátký popis
The subject matter of the Public Contract is supply of instrument shutter as a part of the “Beamline for European Engineering Research” (BEER) instrument, including manufacture, documentation and other performance in accordance with the Contract including its Annexes and delivery of the System to the Buyer at the ESS address in Lund, Kingdom of Sweden, including a free licence to use the System for the needs of the Project and its follow-up phases and installation and alignment of the System.
1️⃣
Místo plnění: Česko🏙️
Místo plnění: Södra Sverige 🏙️
Hlavní místo nebo místo plnění:
“The place of delivery is the Czech Republic, specifically the seat of the Contracting Authority, and for the delivery and installation Lund, Kingdom of Sweden.”
Popis veřejné zakázky:
“The subject matter of the Public Contract is supply of instrument shutter as a part of the “Beamline for European Engineering Research” (BEER) instrument,...”
Popis veřejné zakázky
The subject matter of the Public Contract is supply of instrument shutter as a part of the “Beamline for European Engineering Research” (BEER) instrument, including manufacture, documentation and other performance in accordance with the Contract including its Annexes and delivery of the System to the Buyer at the ESS address in Lund, Kingdom of Sweden, including a free licence to use the System for the needs of the Project and its follow-up phases and installation and alignment of the System.
A detailed description of the subject matter of the Public Contract is provided in the Technical Specification, which forms Annex No. 1 to the Tender Documentation. Further conditions are provided in the binding draft Contract, which forms Annex No. 2 to the Tender Documentation.
The System shall fully comply with all the requirements stipulated in the Contract (including its Annexes) and the Technical Specification.
Zobrazit více Kritéria pro udělení ceny
Cena
Doba trvání smlouvy, rámcové dohody nebo dynamického nákupního systému
Níže uvedený časový rámec je vyjádřen v měsících.
Popis
Doba trvání: 11
Další informace:
“The Contracting Authority reserves the right to make changes to the Public Contract according to Article 3.3 of the Tender Documentation, including...”
Další informace
The Contracting Authority reserves the right to make changes to the Public Contract according to Article 3.3 of the Tender Documentation, including Variations (changes) based on a Modification Order and Postponing deadlines due to delays of related performances of third parties and delays with readiness of site.
Právní, ekonomické, finanční a technické informace Podmínky účasti
Seznam a stručný popis podmínek:
“Supplier shall demonstrate its basic qualification required by Sec. 74 (1) Public Procurement Act.
Supplier shall also demonstrate its professional...”
Seznam a stručný popis podmínek
Supplier shall demonstrate its basic qualification required by Sec. 74 (1) Public Procurement Act.
Supplier shall also demonstrate its professional qualification in relation to the Czech Republic by submitting an extract from the Commercial Register or similar register, if the law requires such registration.
Documentation demonstrating professional qualification of Suppliers needn’t be submitted if the laws in the country where such Supplier is headquartered do not require similar professional qualification.
For complete information please see Art. 6 of the Tender Documentation.
Zobrazit více Technická a odborná způsobilost
Seznam a stručný popis výběrových kritérií:
“The Contracting Authority will require that Suppliers submit:
List of Important Supplies (LIS) provided in the last 5 years prior to commencement of this...”
Seznam a stručný popis výběrových kritérií
The Contracting Authority will require that Suppliers submit:
List of Important Supplies (LIS) provided in the last 5 years prior to commencement of this tendering procedure,
Quality management system certification and
Certification for the welding company.
For more details please see the Tender Documentation.
Zobrazit více Podmínky účasti
Podmínky účasti (technická a odborná způsobilost):
“The Contracting Authority requires that Supplier provide:
- List of important Supplies listing at least 1 important supply. Important supply shall be...”
Podmínky účasti (technická a odborná způsobilost)
The Contracting Authority requires that Supplier provide:
- List of important Supplies listing at least 1 important supply. Important supply shall be understood as: manufacture, delivery and installation of a system including pneumatic motion for load capacity higher than 300 kg and position accuracy better than 0.1 mm (for the end positions),
- valid certificate of the quality management system ISO 9001 and
- valid certificate of ISO 3834-2 certification for the welding company.
For more details please see the Tender Documentation.
Postup Typ postupu
Otevřený postup
Administrativní informace
Lhůta pro doručení nabídek nebo žádostí o účast: 2022-03-04
10:00 📅
Jazyky, ve kterých lze podávat nabídky nebo žádosti o účast: angličtina 🗣️
Jazyky, ve kterých lze podávat nabídky nebo žádosti o účast: čeština 🗣️
Podmínky pro zahájení nabídkového řízení: 2022-03-04
10:01 📅
Podmínky pro otevírání nabídek (Informace o oprávněných osobách a postupu otevírání nabídek):
“The opening of the Bids is a non-public due electronic form of Bids.
The opening of the Bids will take place in accordance with Section 109 of the PPA.”
Doplňující informace Tělo recenze
Název: Úřad pro ochranu hospodářské soutěže
Poštovní adresa: tř. Kpt. Jaroše 7
Poštovní město: Brno
Poštovní směrovací číslo: 60455
Země: Česko 🇨🇿
Telefon: +420 542167111📞
E-mail: posta@uohs.cz📧
Fax: +420 542167112 📠
ADRESA URL: https://www.uohs.cz/🌏 Postup přezkoumání
Přesné informace o lhůtě (lhůtách) pro přezkumné řízení:
“A condition for filing a petition with the Office for the Protection of Competition (OPC) is the filing of objections to the Contracting Authority, which...”
Přesné informace o lhůtě (lhůtách) pro přezkumné řízení
A condition for filing a petition with the Office for the Protection of Competition (OPC) is the filing of objections to the Contracting Authority, which must be delivered within 15 days of the complainant's knowledge of the alleged breach of the law by the Contracting Authority, but no later than till the contract conclusion.
Objections to acts announced in documents that the law requires the Contracting Authority to publish or send to the complainant, have to be delivered to the Contracting Authority within 15 days of their publication or delivery to the complainant.
Where a deadline for submission of bids is specified in the tender procedure, objections to the tender documentation have to be delivered to the Contracting Authority no later than by the end of this deadline.
Objections to a voluntary notice of intent to conclude a contract pursuant to Section 212 (2) of the Act on Public Procurement have to be delivered to the Contracting Authority within 30 days of the publication of the notice.
The Contracting Authority is obliged to handle the objections within 15 days. The petition has to be delivered to the OPC as well as to the Contracting Authority within 10 days from the date on which the complainant received the decision rejecting the objection or within 25 days from dispatch of the objections if the Contracting Authority has not decided on the objections.
Once the contract for a public contract has been concluded, only a petition to impose a ban on the performance of the contract can be filed, even without a prior objection. The petitioner shall deliver the petition to OPC and a copy thereof to the Contracting Authority within 1 month from the date on which the Contracting Authority published the notice on contract conclusion pursuant to Section 212 (2) of the Act on Public Procurement including reasons for awarding the Public contract without publishing a notice of initiation of the procurement procedure, preliminary notice or invitation to submit bids in simplified under-the-threshold procedure, but no later than 6 months after the conclusion of this contract. The petition to impose a ban on the performance of the contract pursuant to Section 254 (1) d) of the Act on Public Procurement shall be delivered by the petitioner to the OPC as well as to the Contracting Authority within 1 month from the date when the Contracting Authority published the notice on contract conclusion based on a Framework Agreement pursuant to Section 137 of the Act on Public Procurement or the notice on contract conclusion in a dynamic purchasing system pursuant to Section 142 of the Act on Public Procurementm but no later than 6 months after the conclusion of this contract.
Within the deadline for the delivery of the petition, the petitioner is obliged to deposit to the account of OPC a surety in the amount of 1 % of the petitioner's bid price for the entire period of performance of the public contract or for the first four years of performance in the case of open-ended contracts, but at least CZK 50 000 and no more than CZK 10,000,000. If the petitioner cannot determine the total bid price, he is obliged to deposit a surety of CZK 100,000. In case of a proposal to impose a ban on performance of the contract, the petitioner is obliged to deposit a surety of CZK 200,000.
Zobrazit více Služba, u které lze získat informace o přezkumném řízení
Název: Úřad pro ochranu hospodářské soutěže
Poštovní adresa: tř. Kpt. Jaroše 7
Poštovní město: Brno
Poštovní směrovací číslo: 60455
Země: Česko 🇨🇿
Telefon: +420 542167111📞
E-mail: posta@uohs.cz📧
Fax: +420 542167112 📠
ADRESA URL: https://www.uohs.cz/🌏
Zdroj: OJS 2022/S 022-054160 (2022-01-27)
Nové veřejné zakázky v souvisejících kategoriích 🆕